Up until the spring of 2020, a FIDIC 1999 Sub-Clause 13.7 [Adjustments for Changes in Legislation] claim was just one of many issues to be resolved, for example, in a delay and disruption claim or a Cost claim. However, the focus it receives in the context of Covid-19 is drastically different. Many in the industry are using the changes in legislation provision to seek financial compensation in a situation that would otherwise potentially only attract an extension of time. Awarding Cost for Covid-19 events regardless of the circumstances may seem to some (Contractors mostly, though there are Employers and Engineers who agree) like the appropriate thing to do, but whether it is correct according to the Contract is a different question.
El efecto del coronavirus en la construcción es amplio y desconocido, en particular, en cómo evaluar el tiempo y el dinero perdido. Por fortuna, los contratos FIDIC proveen varias opciones a las Partes para manejar riesgos y proteger derechos. Este artículo analiza cómo se trataría la pandemia del Covid-19 bajo el Contrato de Construcción de Obras FIDIC 2010 armonizado por el Banco Mundial en español.
Covid-19 has had huge consequences around the world and unfortunately
It has been suggested that FIDIC’s new Emerald Book may be “a contractors’ charter for riches”. 1 This article examines whether this new form of contract for underground works by FIDIC and the International Tunnelling and Underground Space Association is too contractor-biased or whether it provides a sensible and pragmatic risk allocation process, in an area of construction and engineering which is well known for claims. If more risks are placed on the Employer in this form of contract, what are the benefits of the contract compared to, for example, an unamended FIDIC Yellow Book?
Contract clauses that deny a contractor entitlement to an extension of time for concurrent delays caused by both employer and contractor are valid in principle. In North Midland Building Ltd -V- Cyden Homes Ltd  the Court of Appeal of England and Wales has ruled that such clauses do not offend the common law prevention principle. Nor do they give rise to an implied term to prohibit the imposition of delay damages that may result.
Clause 8 contains all the fundamental provisions relating to the start of the Works, the Time for Completion, delays and the entitlement of the Contractor to an extension of time and of the Employer to delay damages, and finally the circumstances in which a suspension of the Works can occur and the implications for the Parties.
Clause 17 - Care of the Works and Indemnities by
Clause 8 - Commencement Delays and Suspension by Taner Dedezade.
In London last week, FIDIC launched its Second Editions of the Red, Yellow and Silver Books. They are big, weighing in at almost a kilo each. The general conditions cover 106 pages with more than 50,000 words, over 50% longer than the 1999 forms. Many improvements have been made, addressing issues that have emerged since 1999. Fans of Dispute Boards will be pleased to see that all three books now have standing boards with more emphasis on dispute avoidance; and that appointment of DB members and enforcement of their decisions have been made easier. Disputes and Arbitration are now dealt with in a separate chapter 21. Here are the most interesting changes to the Yellow Book.
Clause 5 defines a ‘nominated Subcontractor’ as either a Subcontractor who is stated in the Contract as being ‘nominated’; or who the Engineer instructs the Contractor to employ as a Subcontractor under clause 13. The Contractor may object to employing a nominated Subcontractor. A number of grounds are deemed to be reasonable for objecting and these include: where there are reasons to believe that the Subcontractor does not have sufficient resources, competence or financial strength to complete the subcontracted works; where the Subcontractor refuses to agree to indemnify the Contractor for any negligence; or where the Subcontractor does not agree to carry out the works so as not to put the Contractor in breach of its own obligations. If the Employer requires that the Contractor employ a nominated Subcontractor where a reasonable objection has been made then it must agree to indemnify the Contractor. The Contractor is required to pay to the nominated Subcontractor the amounts which the Engineer certifies to be due in accordance with the Subcontract. This sum is then added to the Contract Price as well as any amount for overheads and profit as stated in the appropriate schedule or Appendix to Tender. However, before issuing a Payment Certificate to the Contractor the Engineer may ask for evidence that previous payments have been made to the nominated Subcontractor. If evidence is not provided by the Contractor or the Contractor does not satisfy the Engineer that there are grounds for withholding payment then the Employer may at his discretion pay the nominated Subcontractor directly.