Page Corrigenda 146 For provisions referring to sub-clause 3.7, see
Although Clause 17 is titled ‘Risk and Responsibility’ it also sets out other provisions relating to indemnities, limitation of liability and, unusually, the specific topic of intellectual and industrial property rights. The clause provides that the Contractor assumes responsibility and bears the risk for the care of the works during execution and for remedying any defects during the Defects Notification Period. Risk transfers to the Employer on issue of the Taking–Over Certificate to the extent of works defined as being completed. Generally, in construction contracts ‘risk’ is understood to mean an event or circumstance which causes delay, loss or damage to the Works. A risk can be said to be Employer caused, Contractor caused or neutral. The purpose of risk allocation is to determine which party bears the risk for such events. The Contractor may be required to remediate the damage at his own cost or the Employer may be required to pay for the damaged works. It has been stated that the “FIDIC standard forms are generally recognised as being well balanced because both parties bear parts of the risks arising from the project.”
Clause 8 contains all the fundamental provisions relating to the start of the Works, the Time for Completion, delays and the entitlement of the Contractor to an extension of time and of the Employer to delay damages, and finally the circumstances in which a suspension of the Works can occur and the implications for the Parties.
Clause 14 deals with all aspects of payment. It also deals with the Statement at Completion, the Final Payment Certificate, Discharge and Cessation of the Employer’s Liability. The Clause provides that this is a re-measurement contract and that the quantities stated in the Bill of Quantities are estimated. There is provision for an advance payment to be made to the Contract. Applications for Interim Payment Certificates are made monthly and these must be supported by documents and a report on progress. Unless the amount assessed is less than the minimum amount set out in the Appendix to Tender, the Engineer has 28 days to issue an Interim Payment Certificate, which states the amount the Engineer fairly determines to be due. The Employer thereafter has an obligation to pay the amount certified, in the currencies named in the Appendix to Tender. In the event that payment is not received the Contractor can claim financing charges compounded monthly. Fifty per cent of the retention monies are paid when the Taking-Over Certificate is issued. Where there are Sections then a proportion is paid. The balance of retention is paid on the expiry of the latest Defects Notification Period or, where there are Sections, a proportion at the expiry of the Defects Notification Period for that Section. Within 84 days of receiving the Taking-Over Certificate the Contractor submits a Statement at Completion. This must include an estimate of all sums which the Contractor considers due. Within 56 days of receiving a Performance Certificate, the Contractor submits a Final Statement. The Contractor must also submit with the Final Statement a written discharge which confirms that the total of the Final Statement represents full and final settlement of all moneys due. The Engineer then issues to the Employer a Final Payment Certificate. The Contract states that the Employer shall have no liability to the Contractor except to the extent that the Contractor has included an amount expressly for that matter in the Final Statement and also the Statement at Completion.
The main changes in Clause 16 are the new grounds for suspension and termination: Non-compliance with a final and binding Engineer’s Determination and binding or final and binding DAAB decision, to the extent that such failure constitutes a “material breach” of the Employer’s obligations under the Contract. (Sub-Clauses 16.1(d) and 16.2.1(d)). What constitutes a “material breach” is likely to be the subject of many disputes (see the commentary on Clause 15). Non-receipt of a Notice of the Commencement Date under Sub-Clause 8.1 [Commencement of Works] within 84 days after receiving the Letter of Acceptance. (Sub-Clauses 16.2.1(f)). This is development to ground (h) in the FIDIC Pink (MDB) Book which states: “the Contractor does not receive the Engineer’s instructions recording the agreement of both Parties on the fulfilment of the conditions for the Commencement of the Works under Sub-Clause 8.1 [Commencement of Works]”. It protects the Contractor from the financial consequences of fluctuations in the rates and prices during an extended delay to the start of the Works, although the Contractor ould be entitled to damages for breach of contract in any event. More importantly, it gives the Contractor loss of profit on the entire project. Engagement in corrupt, fraudulent, collusive or coercive practice at any time in relation to the Works or to the Contract. (Sub-Clauses 16.2.1(j).) This introduces parity between the Employer and Contractor. The wording is identical to that under Sub-Clause 15.2.1(h). In the FIDIC 1999 editions, the Employer was entitled to terminate if the Contractor gave or offered an inducement or reward etc. but there was no recipricol arrangement.
The main changes in Clause 15 are the new grounds for termination: Non-compliance with a final and binding Engineer’s Determination (Sub-Clause 15.2.1(a)(ii)) and a binding or final and binding DAAB decision (Sub-Clause 15.2.1(a)(iii)) to the extent that such failure constitutes a “material breach” of the Employer’s obligations under the Contract. Maxing out the Delay Damages (Sub-Clause 15.2.1(c)). There is no requirement for the Delay Damages to have been actually deducted. It is not clear what the position would be if the Contractor claims an EOT and it is granted by the DAAB or arbitrator after termination so that the Delay Damages are reduced below the cap. Would the termination then be unlawful?
In London last week, FIDIC launched its Second Editions of the Red, Yellow and Silver Books. They are big, weighing in at almost a kilo each. The general conditions cover 106 pages with more than 50,000 words, over 50% longer than the 1999 forms. Many improvements have been made, addressing issues that have emerged since 1999. Fans of Dispute Boards will be pleased to see that all three books now have standing boards with more emphasis on dispute avoidance; and that appointment of DB members and enforcement of their decisions have been made easier. Disputes and Arbitration are now dealt with in a separate chapter 21. Here are the most interesting changes to the Yellow Book.
Clause 19 deals with two distinct events: (1) Force Majeure; and (2) release from performance under the law. Force Majeure is often narrowly defined under the laws of many countries; however, within the FIDIC 1999 forms of contract it has a much broader meaning. The terminology used by FIDIC has therefore sometimes been criticized as being misleading.
Click through to read Corbett & Co.'s helpful commentary on FIDIC 1999 book Clause 15