Clause 8 contains all the fundamental provisions relating to the start of the Works, the Time for Completion, delays and the entitlement of the Contractor to an extension of time and of the Employer to delay damages, and finally the circumstances in which a suspension of the Works can occur and the implications for the Parties.
Clause 8 - Commencement Delays and Suspension by Taner Dedezade.
In London last week, FIDIC launched its Second Editions of the Red, Yellow and Silver Books. They are big, weighing in at almost a kilo each. The general conditions cover 106 pages with more than 50,000 words, over 50% longer than the 1999 forms. Many improvements have been made, addressing issues that have emerged since 1999. Fans of Dispute Boards will be pleased to see that all three books now have standing boards with more emphasis on dispute avoidance; and that appointment of DB members and enforcement of their decisions have been made easier. Disputes and Arbitration are now dealt with in a separate chapter 21. Here are the most interesting changes to the Yellow Book.
Clause 19 deals with two distinct events: (1) Force Majeure; and (2) release from performance under the law. Force Majeure is often narrowly defined under the laws of many countries; however, within the FIDIC 1999 forms of contract it has a much broader meaning. The terminology used by FIDIC has therefore sometimes been criticized as being misleading.
Click through to read Corbett & Co.'s helpful commentary on FIDIC 1999 book Clause 15
Clause 4 sets out various obligations which fall on the Contractor under the Contract and which cannot easily be classified elsewhere. The obligations under Clause 4 are of a wide range covering 24 different topics. Sub-Clause 4.1 sets out the Contractor’s general obligation to carry out his duties in accordance with the contract. Clause 4 of the FIDIC Red Book 1999 amalgamates various Contractor obligations under one provision. However this Clause 4 is not exclusive as there are also other Contractor obligations scattered throughout the Contract. Other significant general obligations which could equally have been included in Clause 4 (and which should be read in conjunction with this Clause 4) are as follows: • Sub-Clause 1.3 [Communications] • Sub-Clause 1.7 [Assignment] • Sub-Clause 1.8 [Care and Supply of Documents] • Sub-Clause 1.9 [Delayed Drawings or Instructions] • Sub-Clause 1.10 [Employer’s Use of Contractor’s Documents] • Sub-Clause 1.12 [Confidential Details] • Sub-Clause 1.13 [Compliance with Laws] • Clause 6 [Staff and Labour] • Clause 7 [Plant, Materials and Workmanship] • Sub-Clause 8.2 [Time for Completion] • Sub-Clause 8.3 [Programme]
Sub-Clause 13.1 deals with the right of the Engineer to vary the Contract. This right can be exercised at any time up to the issue of the Taking-Over Certificate. Sub-Clause 13.2 deals with value engineering and permits the Contractor to propose a change which will benefit the Employer. The proposal is prepared at the cost of the Contractor, who designs the change. Sub-Clause 13.3 deals with the procedure prior to the Engineer instructing a variation. The Engineer may request a proposal from the Contractor. However, while the Contractor is preparing the proposal it must proceed with the works. Sub-Clause 13.4 deals with payment in applicable currencies. Sub-Clause 13.5 deals with Provisional Sums and ought to be read with Sub-Clause 220.127.116.11 which defines Provisional Sum as follows:- “a sum (if any) which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Materials or services under Sub-Clause 13.5 [Provisional Sums].” The Provisional Sum can only be used where there is an Engineer’s instruction and the Contractor receives payment for only the work done to which the Provisional Sum relates. Sub-Clause 13.6 deals with daywork. This is where work of a minor or incidental nature is to be carried out. The work is then valued in accordance with the Daywork Schedule in the Contract or if there is no Daywork Schedule then the alternative method of payment as prescribed in the Contract. Sub-Clause 13.7 deals with the Cost arising from changes in the Laws of the Country which affect the Contractor in performance of his obligations under the Contract. Where the Contractor suffers delay or additional Cost then it must give notice under Sub-Clause 20.1 of the Contract. Sub-Clause 13.8 deals with adjustments for changes in cost. This Sub-Clause only applies where the “table of adjustment data” included in the Appendix to Tender has been completed. If the Sub-Clause does apply then the amounts payable to the Contractor for rises and fall in the cost of the Works are adjusted by a formula.
Clause 5 defines a ‘nominated Subcontractor’ as either a Subcontractor who is stated in the Contract as being ‘nominated’; or who the Engineer instructs the Contractor to employ as a Subcontractor under clause 13. The Contractor may object to employing a nominated Subcontractor. A number of grounds are deemed to be reasonable for objecting and these include: where there are reasons to believe that the Subcontractor does not have sufficient resources, competence or financial strength to complete the subcontracted works; where the Subcontractor refuses to agree to indemnify the Contractor for any negligence; or where the Subcontractor does not agree to carry out the works so as not to put the Contractor in breach of its own obligations. If the Employer requires that the Contractor employ a nominated Subcontractor where a reasonable objection has been made then it must agree to indemnify the Contractor. The Contractor is required to pay to the nominated Subcontractor the amounts which the Engineer certifies to be due in accordance with the Subcontract. This sum is then added to the Contract Price as well as any amount for overheads and profit as stated in the appropriate schedule or Appendix to Tender. However, before issuing a Payment Certificate to the Contractor the Engineer may ask for evidence that previous payments have been made to the nominated Subcontractor. If evidence is not provided by the Contractor or the Contractor does not satisfy the Engineer that there are grounds for withholding payment then the Employer may at his discretion pay the nominated Subcontractor directly.