Clause 14 deals with all aspects of payment. It also deals with the Statement at Completion, the Final Payment Certificate, Discharge and Cessation of the Employer’s Liability. The Clause provides that this is a re-measurement contract and that the quantities stated in the Bill of Quantities are estimated. There is provision for an advance payment to be made to the Contract. Applications for Interim Payment Certificates are made monthly and these must be supported by documents and a report on progress. Unless the amount assessed is less than the minimum amount set out in the Appendix to Tender, the Engineer has 28 days to issue an Interim Payment Certificate, which states the amount the Engineer fairly determines to be due. The Employer thereafter has an obligation to pay the amount certified, in the currencies named in the Appendix to Tender. In the event that payment is not received the Contractor can claim financing charges compounded monthly. Fifty per cent of the retention monies are paid when the Taking-Over Certificate is issued. Where there are Sections then a proportion is paid. The balance of retention is paid on the expiry of the latest Defects Notification Period or, where there are Sections, a proportion at the expiry of the Defects Notification Period for that Section. Within 84 days of receiving the Taking-Over Certificate the Contractor submits a Statement at Completion. This must include an estimate of all sums which the Contractor considers due. Within 56 days of receiving a Performance Certificate, the Contractor submits a Final Statement. The Contractor must also submit with the Final Statement a written discharge which confirms that the total of the Final Statement represents full and final settlement of all moneys due. The Engineer then issues to the Employer a Final Payment Certificate. The Contract states that the Employer shall have no liability to the Contractor except to the extent that the Contractor has included an amount expressly for that matter in the Final Statement and also the Statement at Completion.
Clause 3 deals with the duties and obligations of the Engineer and his assistants. Sub-Clause 3.1 deals with the role and duties of the Engineer. The Engineer is deemed to act for the Employer. The Engineer has no authority to relieve the Contractor of his duties, obligations or responsibilities under the Contract; nor can the Engineer amend the Contract. Under Sub-Clause 3.2 the Engineer can delegate authority to any assistants; however, the Engineer cannot delegate the responsibility to make Determinations. Under Sub-Clause 3.3 the Engineer may issue instructions or modified Drawings at any time, which are necessary for the execution of the Works. If the instruction constitutes a Variation, then it is dealt with under Clause 13 [Variations and Adjustments]. The Contractor is required to comply with any instruction given by the Engineer or delegated assistant. Sub-Clause 3.4 deals with the replacement of the Engineer. The Employer must not replace the Engineer with someone against whom the Contractor raises reasonable objection. Sub-Clause 3.5 deals with Determinations. When making a Determination the Engineer should consult with each of the Parties and, if agreement cannot be reached, make a fair determination in accordance with the Contract, taking due regard of all relevant circumstances. Both Parties are required to give effect to any Determination unless, or until, it is revised under Sub-Clause 20.1 [Claims, Disputes and Arbitration].
The main changes in Clause 15 are the new grounds for termination: Non-compliance with a final and binding Engineer’s Determination (Sub-Clause 15.2.1(a)(ii)) and a binding or final and binding DAAB decision (Sub-Clause 15.2.1(a)(iii)) to the extent that such failure constitutes a “material breach” of the Employer’s obligations under the Contract. Maxing out the Delay Damages (Sub-Clause 15.2.1(c)). There is no requirement for the Delay Damages to have been actually deducted. It is not clear what the position would be if the Contractor claims an EOT and it is granted by the DAAB or arbitrator after termination so that the Delay Damages are reduced below the cap. Would the termination then be unlawful?
Clause 14 - Contract Price and Payment by George Rosenberg.
In London last week, FIDIC launched its Second Editions of the Red, Yellow and Silver Books. They are big, weighing in at almost a kilo each. The general conditions cover 106 pages with more than 50,000 words, over 50% longer than the 1999 forms. Many improvements have been made, addressing issues that have emerged since 1999. Fans of Dispute Boards will be pleased to see that all three books now have standing boards with more emphasis on dispute avoidance; and that appointment of DB members and enforcement of their decisions have been made easier. Disputes and Arbitration are now dealt with in a separate chapter 21. Here are the most interesting changes to the Yellow Book.
The Engineer is deemed to act for the Employer and is essentially the Employer’s agent under the FIDIC Red Book 1999. He is not a wholly impartial intermediary, unless such a role is specified in the Particular Conditions, and there is no general obligation under the FIDIC Red Book 1999 for the Engineer to act independently or impartially. However, when he is required to make a determination under Sub-Clause 3.5, he is obliged to make it a fair determination and when he is obliged to issue an Interim Payment Certificate under Sub-Clause 14.6, or a Final Payment Certificate under Sub-Clause 14.13, he must fairly determine the amount due.
Clause 4 sets out various obligations which fall on the Contractor under the Contract and which cannot easily be classified elsewhere. The obligations under Clause 4 are of a wide range covering 24 different topics. Sub-Clause 4.1 sets out the Contractor’s general obligation to carry out his duties in accordance with the contract. Clause 4 of the FIDIC Red Book 1999 amalgamates various Contractor obligations under one provision. However this Clause 4 is not exclusive as there are also other Contractor obligations scattered throughout the Contract. Other significant general obligations which could equally have been included in Clause 4 (and which should be read in conjunction with this Clause 4) are as follows: • Sub-Clause 1.3 [Communications] • Sub-Clause 1.7 [Assignment] • Sub-Clause 1.8 [Care and Supply of Documents] • Sub-Clause 1.9 [Delayed Drawings or Instructions] • Sub-Clause 1.10 [Employer’s Use of Contractor’s Documents] • Sub-Clause 1.12 [Confidential Details] • Sub-Clause 1.13 [Compliance with Laws] • Clause 6 [Staff and Labour] • Clause 7 [Plant, Materials and Workmanship] • Sub-Clause 8.2 [Time for Completion] • Sub-Clause 8.3 [Programme]
Clause 10 deals with the Taking-Over of the Works, Sections, or parts of the Works. Sub-Clause 10.1 deals with the Taking-Over of the Works and Sections. Taking-Over by the Employer happens when the Works (a) pass the Tests on Completion; (b) are substantially complete; (c) any contractual requirements relating to Taking-Over have been met; and (d) the Taking-Over Certificate has been issued or is deemed to have been issued. Sub-Clauses 10.2 and 10.3 deal with deemed Taking-Over where the Employer uses part of the Works or interferes with the Tests on Completion for more than 14 days. The failure to issue a Taking-Over Certificate by the Engineer, where the Employer has taken into commercial use the Works, will amount to a breach of contract.
Read the full article here.
There is a substantial difference between the payment provisions of the FIDIC 1999 Red and Yellow Books compared with the Silver Book. This article explores how a court in Queensland (Australia) has dealt with the Silver Book’s provision. Contractors have good cause to be wary.
This article discusses whether the recently issued FIDIC Guidance Memorandum really does provide the answer to the vexed question of enforcement of binding, but not yet final DAB decisions. On 1 April 2013 the FIDIC Contracts Committee issued a Guidance Memorandum to users which is intended to be used with the Conditions of Contract for Construction (the ‘Red Book’), the Conditions of Contract for Plant and Design-Build (the ‘Yellow Book’), and the Conditions of Contract for EPC/Turnkey Projects (the ‘Silver Book’). The FIDIC Contracts Committee have stated that compliance with the guidance is highly recommended when using the 1999 FIDIC Red, Yellow or Silver Books. This article considers briefly whether the Guidance Memorandum is either necessary or useful.